Artificial Intelligence
Builders Company
Developers/Billingsley Company
BC
Billingsley CompanyDallas, United States · founded 1978 · 1 active markets
PRIVATE

Billingsley Company develops and manages master-planned communities across North Texas, combining office, multifamily housing, retail, industrial, land and mixed-use projects for businesses, residents and institutional tenants.

Years in business
48
founded 1978
LinkedIn headcount
287
employees, as shown on LinkedIn · size band 51–200
Units delivered
more than 8,500 multifamily units
as the company states it
Projects last researched October 11, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
Billingsley Property Services, Inc.1
Headquarters
1722 Routh Street, Suite 7701, Dallas1, United States
Founded
19781
Entity type
PRIVATE1
Business model
offplan for sale1, build to rent1, commercial1, mixed use1, masterplan1, contracting1
Markets
1 market listed
What they build
Residential, for rent (6 of 10) · Office (3 of 10) · Industrial (1 of 10)
Full dossier in About →

Delivery record

5 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
0.0 mo
the middle of 5 scored projects
Average delay
+2.2 mo
the same projects, pulled by the worst
Average time to deliver
1.9 yrs
start to completion, over 3 delivered projects
Worst slip
+12.0 mo
Denton Distribution Center · +1.0 to +23.0
3
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
0
red rows below

Against other developers

5 date-assessed here · 226 developers, 839 date-assessed projects in United States
Median delay
Billingsley Company·226 developers in United States
0.0 mo vs +4.5 mo
this developer 4.5 mo better
The typical project on each side.
Average delay
Billingsley Company·226 developers in United States
+2.2 mo vs +7.5 mo
this developer 5.3 mo better
Both pulled by their worst few.
On time
Billingsley Company·226 developers in United States
60% vs 56%
this developer 4 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Billingsley Company·226 developers in United States
1.9 yrs vs 2.9 yrs
this developer 1.0 yrs faster
Start to completion, over 3 delivered here and 692 in the market.
Projects and timelines in Track Record →

Resident experience

6 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.2/ 10
Weighted judgment across build and operations · from 6 of 6 rated buildings
Little structure evidence (2 of 6 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
8.2/ 10
Fabric, services, waterproofing, envelope · from 2 of 6 rated buildings
Management & living
8.2/ 10
Upkeep, response times, amenities, community · from 6 of 6 rated buildings

Against other developers

6 rated here · 245 developers, 1272 rated buildings in United States
Overall rating
Billingsley Company · 245 other developers in United States
8.2 vs 7.8
this developer 0.4 better
The weighted verdict on each side. From 6 of 6 rated buildings here and 1272 in the market.
Structure & systems
Billingsley Company · 245 other developers in United States
— vs 7.0
Too few buildings with this score here to compare (2 of 6)
Fabric and engineering only — fixed at handover. From 2 of 6 rated buildings here and 537 in the market.
Management & living
Billingsley Company · 245 other developers in United States
8.2 vs 7.4
this developer 0.8 better
Upkeep and response — belongs to whoever runs the building now. From 6 of 6 rated buildings here and 1232 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.
Ratings by building →

Awards & recognition

All awards →

Risks & source coverage

  • LEGAL Filed November 10, 2023; settled February 24, 2025; dismissed with prejudice March 5, 2025 A former marketing director sued Billingsley Property Services II, Inc., d/b/a The Billingsley Company, alleging disability discrimination, interference and retaliation under the FMLA, and ERISA-related discrimination after her November 14, 2022 termination; Billingsley denied the allegations, and the case was settled and dismissed with prejudice on March 5, 2025, without a merits finding.
  • RISK Complaints reported May 2025, May 2024, July 2024, January 2024 and earlier; BBB page current as of 2026 BBB records reported multiple resident billing and move-out disputes involving Billingsley-managed properties, including allegations of incorrect rent or security-deposit charges, unexplained cleaning or accelerated-rent charges, and delayed refunds; the records also show several company responses and some resolved complaints, so these are consumer allegations rather than adjudicated findings.
Record status
active
Company sources
119 source entries across 119 fields
Projects tracked
10 · 10 completed in assessment
All flags and sources →

Track Record

Delivery record

5 date-assessed of 10 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-15 through 2026-10-15, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
10
within the rolling ten-year window
Median delay
0.0 mo
the middle of 5 scored projects
Average delay
+2.2 mo
the same projects, pulled by the worst
Average time to deliver
1.9 yrs
start to completion, over 3 delivered projects
Worst slip
+12.0 mo
Denton Distribution Center · +1.0 to +23.0
3
early or less than 6 months late
6 to 12 months late
2
yellow rows below
Over 12 months late
0
red rows below

Against other developers

5 date-assessed here · 226 developers, 839 date-assessed projects in United States
Median delay
Billingsley Company·226 developers in United States
0.0 mo vs +4.5 mo
this developer 4.5 mo better
The typical project on each side.
Average delay
Billingsley Company·226 developers in United States
+2.2 mo vs +7.5 mo
this developer 5.3 mo better
Both pulled by their worst few.
On time
Billingsley Company·226 developers in United States
60% vs 56%
this developer 4 pts better
Share of date-assessed projects delivered early or less than 6 months after the original target. Exactly 6 months late is excluded.
Average time to deliver
Billingsley Company·226 developers in United States
1.9 yrs vs 2.9 yrs
this developer 1.0 yrs faster
Start to completion, over 3 delivered here and 692 in the market.
The market here is United States: every other developer whose head office is in the same country, because planning regimes and reporting norms move together within one. It is not a city, a sector or a size band. Read the two delay figures together. A median close to the market with a much better average means no single disaster; the reverse means one project is carrying the record. Time to deliver runs from the earliest start we hold to the completion itself — a construction start where a source gave one, otherwise a sales launch, otherwise the launch year read as its January. A handover the sources place only inside a year is read as that December, so a duration is the widest the record allows rather than the flattering end of it. Only delivered projects dated at both ends count, so it is taken over fewer projects than the delay figures, and a long build is not a fault: a tower is not a villa run. Sourced figures only, both sides, and values taken from documents held on file are excluded here — a developer who shares their records should not score better than one who does not.

Construction start to handover

10 of 10 projects dated · 6 places
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
Dallas, United States
Denton, United States
Plano, United States
The Colony, United States
Coppell, United States
Carrollton, United States
201920202021202220232024202520262027todayDALLAS, UNITED STATEScompleted, no target publishedon timeverifiedDENTON, UNITED STATES+12 moverifiedPLANO, UNITED STATEScompleted, no target publisheddates under reviewTHE COLONY, UNITED STATEScompleted, no target publishedCOPPELL, UNITED STATES−0.5 moverified+6 moverifiedcompleted, no target publishedCARROLLTON, UNITED STATES−6.5 moverified
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures. 4 turned out to be about something else — a phase, a neighbour, the wider masterplan — and are marked off-subject.

Building & Livability Ratings

Resident experience

6 of 10 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
8.2/ 10
Weighted judgment across build and operations · from 6 of 6 rated buildings
Little structure evidence (2 of 6 buildings) — this rests mainly on whole-building and living reviews.
Structure & systems
8.2/ 10
Fabric, services, waterproofing, envelope · from 2 of 6 rated buildings
Management & living
8.2/ 10
Upkeep, response times, amenities, community · from 6 of 6 rated buildings

Against other developers

6 rated here · 245 developers, 1272 rated buildings in United States
Overall rating
Billingsley Company · 245 other developers in United States
8.2 vs 7.8
this developer 0.4 better
The weighted verdict on each side. From 6 of 6 rated buildings here and 1272 in the market.
Structure & systems
Billingsley Company · 245 other developers in United States
— vs 7.0
Too few buildings with this score here to compare (2 of 6)
Fabric and engineering only — fixed at handover. From 2 of 6 rated buildings here and 537 in the market.
Management & living
Billingsley Company · 245 other developers in United States
8.2 vs 7.4
this developer 0.8 better
Upkeep and response — belongs to whoever runs the building now. From 6 of 6 rated buildings here and 1232 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.

By building

6 rated · 4 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
August HillsValley Ranch, Dallas541 units
8.6/ 10
—/ 10
9.1/ 10

Birdeye’s 4.7/5 from 129 reviews is the largest review base and converts to 9.1. Google’s 4.8/5 from 76 reviews is consistent. The score is reduced for the serious move-in leak/build-problem report and slow follow-up; structure remains unscored because no building-wide structural rating exists.

+ New construction+ Modern finishes+ Open layouts+ Smart-home features+ Energy-efficient appliances
− Reported move-in leak− Unspecified build problems− Work-order follow-up delay
Not found in sources: No engineering review · Limited long-term evidence
+ Helpful leasing staff+ Responsive management+ Maintenance praise+ Resort-style pools+ Dog parks and playground
− Move-in service delay− Unresolved work orders− Premium pricing concern− Limited operating history− Serious move-in complaint

The available infrastructure evidence is limited because the community opened in 2025. One September 2025 review reported “a leak and a slew of other problems” at move-in and the need to chase work orders; other displayed reviews praise newness and cleanliness but do not independently assess plumbing, HVAC or structural systems.

Displayed reviews are predominantly positive: residents call the property “newest and cleanest,” describe management as “very helpful,” and praise staff who went “above and beyond.” The contrary account says a move-in leak and other problems required repeated follow-up because staff were “slow to address the problems”; the official site lists pools, fitness, dog parks, a playground and clubrooms, but these are amenities claims rather than resident ratings.

Wylder SquareCarrollton372 units
8.5/ 10
8.2/ 10
8.5/ 10

The largest published review base is the 4.4/5 Google aggregate from 180 reviews, which converts to 8.2/10 under the requested curve. The sampled written reviews reinforce strong maintenance, staff and cleanliness performance and add roughly 0.3 points for repeated praise, while the negative reports are isolated rather than recurring severe failures. Structure is scored only from the limited physical-condition evidence, chiefly fast AC, elevator and appliance repairs; living is higher because the operational evidence is more extensive.

+ Fast AC repairs+ Responsive elevator repairs+ Quick appliance repairs+ Modern finishes+ Well-maintained interiors
− Small laundry appliances− Occasional elevator issues− Occasional appliance issues− Disputed toilet-seat charge− Reported hallway odor
+ Fast maintenance+ Clean hallways+ Helpful staff+ Strong amenities+ Well-kept trash areas
− Hallway urine odor− Dog waste in halls− Leasing communication glitches− Disputed move-out fees− Pet-policy enforcement concern

Published resident feedback is favorable on day-to-day systems: one reviewer said maintenance restored an AC unit “within 30 minutes,” while another said elevator, parking-gate and appliance issues were fixed “the same day or very quickly.” The available reviews do not report framework, plumbing, electrical, HVAC-design or waterproofing failures; the main physical-condition criticism is a single account of persistent hallway urine odor and dog waste, plus a complaint about small stackable laundry units.

Residents commonly praise fast maintenance, staff professionalism and cleanliness: one reviewer called the property “overall clean” with “extremely fast” maintenance, and another described the hallways as “spotless.” The negative sample is materially narrower but specific, alleging hallways that “consistently smell like straight-up urine,” fresh dog waste, indifferent management, disputed move-out charges and glitchy tour communication.

Hastings EndCypress Waters, Dallas499 units
8.4/ 10
—/ 10
8.4/ 10

Birdeye provides the largest published review base at 4.5/5 from 241 reviews, which converts to 8.5/10 and sets the level. LocalityBiz is directionally consistent at 4.6/5 from 169 reviews, while the written themes add recurring praise for staff and amenities but also recurring moderate concerns about sound insulation and maintenance response.

+ Modern design+ Clean interiors+ Distinctive finishes+ Lake views+ Resort-style pool
− Thin walls− Noise insulation concerns− Musty hallways− Balcony spider complaints− Trash-chute problems
+ Friendly staff+ Responsive leasing team+ Fast application process+ Lake and trail access+ Strong amenity appeal
− Slow maintenance response− Unreturned calls− Noise complaints− Amenity reservation charges− Pest complaints

Published resident feedback is mixed on physical conditions. Positive reviews call the apartments “modern, clean, and beautifully designed,” while negative feedback reports “zero insulation,” “paper thin” walls, musty hallways, pests and recurring trash-chute problems; no independently published engineering or systems score was found.

Day-to-day reviews praise the staff repeatedly: one resident said the team was “friendly, competent and get the job done quickly,” and another described the leasing staff as “kind, patient and professional.” The negative evidence is operationally important, however: reviewers report unanswered calls, maintenance that “take[s] forever,” noise, pests and a high-cost amenity-reservation policy.

The BeaconBeacon Square, Plano539 units
8.4/ 10
8.2/ 10
Find My Place 5/5 · 5 reviews · findmyplace.co
Find My Place publishes 5/5 from 5 reviews. Adjusted for where resident ratings usually fall, and weighted toward the 6.5 midpoint (more strongly the fewer the reviews), that gives 8.2.
8.2/ 10
Find My Place 5/5 · 5 reviews · findmyplace.co
Find My Place publishes 5/5 from 5 reviews. Adjusted for where resident ratings usually fall, and weighted toward the 6.5 midpoint (more strongly the fewer the reviews), that gives 8.2.

The 4.4/5 Birdeye aggregate, based on 165 reviews, is the largest reported review base and converts to 7.0/10 under the requested curve. Repeated praise for staff, maintenance, amenities and cleanliness supports a modest upward adjustment, while the limited move-in-readiness complaint prevents a larger increase; no independent material dissent or structure evidence was found.

+ Responsive staff+ Fast maintenance+ Resort-style pools+ Walkable retail+ Clean common areas
− Initial move-in readiness− Uncovered top-floor parking
Not found in sources: Limited structural feedback · No published security detail · No published systems detail

no notes returned

no links returned

Published resident feedback is strongly positive about daily life: one review says the community “remains clean,” while another praises pools, BBQ areas and dog parks and reports an AC repair completed “within an hour.” The principal negatives are limited and operational: a resident mentioned issues at move-in that were fixed quickly and asked for covered parking on the garage’s top floor; the available reviews do not provide meaningful evidence about security or building systems.

Sage Hill at Cypress WatersCoppell School District, Coppell383 units
8.0/ 10
—/ 10
8.0/ 10

Birdeye’s building-level 4.3/5 rating from 161 reviews is the largest published review base and converts to 7.9/10 under the specified curve. Google’s building-level result is also 4.3/5, so there is no material platform disagreement; the reported recurring praise and complaints produce a small net upward commentary adjustment, yielding 8.0/10. No physical-condition evidence was published, so structure is unevidenced rather than marked down.

+ Prompt maintenance+ Friendly leasing staff+ Responsive management+ Well-kept grounds+ Pool and community amenities
− Management communication gaps− Tenant-unfriendly policies− Thin walls− Noise transfer− Cost concerns

no notes returned

no links returned

Published resident feedback is generally favorable about daily operations: one resident called maintenance “very prompt and efficient,” while another said requests were handled “within a couple of hours”; other reviews praise friendly staff, a well-kept park and pool, and a safe, family-friendly setting. The negative feedback is operational rather than structural, including a recent complaint that management concerns were “often ignored,” an older complaint about tenant-unfriendly policies, and a report that “the walls are so thin” that upstairs movement was audible.

The ChloeThe Colony418 units
7.5/ 10
—/ 10
7.2/ 10

Birdeye’s 4.1/5 aggregate from 80 reviews is the largest reported review base and sets the anchor at 7.3/10 on the specified conversion curve. The score is nudged slightly down because several sampled reviews repeat operational and security complaints, with some offset from repeated praise for maintenance, cleanliness and staff responsiveness. No separate structural score is published, so structure remains unevidenced rather than penalized.

+ Good apparent condition+ Effective maintenance+ Clean common areas+ Quiet interiors reported+ Well-kept property
− Thin-wall complaints− Garage reliability complaint− Broken-gate complaint
Not found in sources: No published engineering detail · No published plumbing/HVAC detail
+ Responsive leasing staff+ Fast maintenance response+ Clean property+ Updated pool and fitness room+ Quiet, accessible location
− Package-theft complaints− Parking enforcement complaints− Management responsiveness concerns− Broken-gate complaint− Garage reliability complaint

Published resident feedback includes positive operational observations rather than an engineering assessment: one reviewer said the property was “in great condition,” while another said maintenance was “consistently excellent” and work was done “right the first time.” Countervailing physical-system complaints include “Thin walls,” a “Garage is always broken,” and “broken gates”; no source located for this report publishes detailed plumbing, HVAC, electrical, waterproofing or structural scores.

The positive day-to-day picture is strong in the sampled resident feedback: reviewers describe maintenance as “consistently excellent,” the property as “very clean,” and the pool, fitness room and clubhouse as “impeccable and very up to date.” However, Birdeye also carries complaints that packages were stolen, gates and the garage were unreliable, and management “does nothing” about parking or security concerns, so the lived experience is not uniformly positive.

Only buildings that have reached handover are rated. 4 of 10 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
Billingsley Property Services, Inc.
Headquarters
1722 Routh Street, Suite 770, Dallas, United States
75201
Founded
1978
Dallas, US
Entity type
PRIVATE
Revenue
USD 44.89 million
Business model
offplan for sale, build to rent, commercial, mixed use, masterplan, contracting

Offices

head office and 1 other
The Colony

Sources: office cities

SOCIALdate not shown in source

Billingsley Company

LinkedIn
Offices: dallas, texas, united states (US), the colony, texas, united states (US)
value seen: The Colony
value paraphrased from this source
https://www.linkedin.com/company/billingsley-company

Partners

4 partners
City of Allen
government partner

The company worked with Allen on the Allen portion of Sloan Corners, which received a reinvestment-zone and tax-increment-finance designation.

City of Fairview
government partner

The company worked with Fairview on the Fairview portion of the 500-acre Sloan Corners mixed-use development.

Petefish family
landowner

The company worked with the Petefish family, identified as the prior landowners, to develop the Sloan Corners property.

Adolfson & Peterson Construction
contractor

Adolfson & Peterson Construction completed Billingsley Company’s International Business Park 18 building.

Sources: name

PRESS2023-05-31

Billingsley Co. to Begin Work on $3B DFW Mixed-Use Project

Commercial Property Executive
Billingsley Co. is working with both Fairview and Allen to develop the massive project
value seen: Allen
https://www.commercialsearch.com/news/billingsley-co-to-begin-work-on-3b-dfw-mixed-use-project/

Sources: summary

PRESS2023-05-31

Billingsley Co. to Begin Work on $3B DFW Mixed-Use Project

Commercial Property Executive
Billingsley Co. is working with both Fairview and Allen to develop the massive project
value seen: working with both Fairview and Allen
value paraphrased from this source
https://www.commercialsearch.com/news/billingsley-co-to-begin-work-on-3b-dfw-mixed-use-project/

Sources: name

PRESS2023-05-31

Billingsley Co. to Begin Work on $3B DFW Mixed-Use Project

Commercial Property Executive
Billingsley Co. is working with both Fairview and Allen to develop the massive project
value seen: Fairview
https://www.commercialsearch.com/news/billingsley-co-to-begin-work-on-3b-dfw-mixed-use-project/

Sources: summary

PRESS2023-05-31

Billingsley Co. to Begin Work on $3B DFW Mixed-Use Project

Commercial Property Executive
Billingsley Co. is working with both Fairview and Allen to develop the massive project
value seen: working with both Fairview and Allen
value paraphrased from this source
https://www.commercialsearch.com/news/billingsley-co-to-begin-work-on-3b-dfw-mixed-use-project/

Sources: name

PRESS2023-05-25

Billingsley’s $3B Allen Project Nears Construction Start

The Real Deal
The firm has been working with city officials and landowners, the Petefish family, to develop the property.
value seen: Petefish family
https://www.therealdeal.com/texas/dallas/2023/05/25/billingsleys-3b-allen-project-taking-off/

Sources: summary

PRESS2023-05-25

Billingsley’s $3B Allen Project Nears Construction Start

The Real Deal
The firm has been working with city officials and landowners, the Petefish family, to develop the property.
value seen: landowners, the Petefish family
value paraphrased from this source
https://www.therealdeal.com/texas/dallas/2023/05/25/billingsleys-3b-allen-project-taking-off/

Sources: name

COMPANY2022-01-31

News + Press – Billingsley Company

Billingsley Company
Adolfson & Peterson Construction (AP) has completed Billingsley Company’s International Business Park 18 building
value seen: Adolfson & Peterson Construction
https://www.billingsleyco.com/news-press/

Sources: summary

COMPANY2022-01-31

News + Press – Billingsley Company

Billingsley Company
Adolfson & Peterson Construction (AP) has completed Billingsley Company’s International Business Park 18 building
value seen: has completed Billingsley Company’s International Business Park 18 building
https://www.billingsleyco.com/news-press/

Registrations & licences

COMPANY NUMBER126341900
Texas Secretary of State · US · Active
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries
United Statesactive 10 projects tracked

What they build

3 types
Residential, for rent6 of 10
Office3 of 10
Industrial1 of 10
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
LB
Lucy Billingsley
Lucy Billingsley co-founded Billingsley Company with Henry and has spent her career developing and managing commercial real estate. Her background includes leading Dallas Market Center and Crow Design Centers, and she holds civic and institutional board roles.
Current title
Partner
since 1978
Experience
no career length stated
Companies before
Dallas Market Center
Education
The University of TexasB.B.A. in finance
Other boards
Klyde Warren Park
Known for
Founder
https://linkedin.com/in/lucy-billingsley-bb10321b4
I don’t consider this a view from the top, but from the way up. Urban Land Institute 2016-11-07https://urbanland.uli.org/development-business/view-top-branching-family-business

Sources: degree

OTHERdate not shown in source

JA Lucy Billingsley Bio – Junior Achievement Dallas Business Hall of Fame

Junior Achievement Dallas Business Hall of Fame
Lucy Billingsley was born and raised in Dallas and is a graduate of The University of Texas with a B.B.A. in finance.
value seen: B.B.A. in finance
https://jadallasbusinesshalloffame.org/lucy-billingsley-bio/

Sources: institution

OTHERdate not shown in source

JA Lucy Billingsley Bio – Junior Achievement Dallas Business Hall of Fame

Junior Achievement Dallas Business Hall of Fame
Lucy Billingsley was born and raised in Dallas and is a graduate of The University of Texas with a B.B.A. in finance.
value seen: The University of Texas
https://jadallasbusinesshalloffame.org/lucy-billingsley-bio/

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Lucy Billingsley
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: linkedin page

SOCIALdate not shown in source

Lucy Billingsley

LinkedIn
Partner at Billingsley Company
value seen: https://linkedin.com/in/lucy-billingsley-bb10321b4
https://linkedin.com/in/lucy-billingsley-bb10321b4

Sources: other boards

OTHERdate not shown in source

LUCY BILLINGSLEY

Billingsley Company
She is currently a board member of Klyde Warren Park, KERA and the Hudson Institute.
value seen: Klyde Warren Park
https://media.billingsleyco.com/m/142ea9cda897f024/original/BIO-Lucy_Billingsley.pdf

Sources: previous companies

OTHERdate not shown in source

JA Lucy Billingsley Bio – Junior Achievement Dallas Business Hall of Fame

Junior Achievement Dallas Business Hall of Fame
Prior to her focus on Billingsley Company, Lucy was Chief Executive Officer of the Dallas Market Center and the Crow Design Centers in Dallas, Houston and Boston.
value seen: Dallas Market Center
https://jadallasbusinesshalloffame.org/lucy-billingsley-bio/

Sources: quote

PRESS2016-11-07

View from the Top: Branching Out from the Family Business - Urban Land Magazine

Urban Land Institute
“I don’t consider this a view from the top, but from the way up,” said Billingsley in response to a query from WLI global chair Wendy Rowden, president of 42nd Street Development Corporation, about how she chose a career in real estate.
value seen: I don’t consider this a view from the top, but from the way up.
https://urbanland.uli.org/development-business/view-top-branching-family-business

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Partner
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: since

COMPANYdate not shown in source

LUCY BILLINGSLEY

Billingsley Company
Lucy started Billingsley Company with her husband, Henry, in 1978 to manage their growing real estate portfolio in the Dallas/Fort Worth area.
value seen: 1978
https://media.billingsleyco.com/m/142ea9cda897f024/original/BIO-Lucy_Billingsley.pdf

Sources: summary

COMPANYdate not shown in source

LUCY BILLINGSLEY

Billingsley Company
Lucy Billingsley has spent her career in real estate, developing and managing commercial developments. Lucy started Billingsley Company with her husband, Henry, in 1978 to manage their growing real estate portfolio in the Dallas/Fort Worth area.
value seen: Lucy Billingsley co-founded Billingsley Company with Henry and has spent her career developing and managing commercial real estate. Her background includes leading Dallas Market Center and Crow Design Centers, and she holds civic and institutional board roles.
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://media.billingsleyco.com/m/142ea9cda897f024/original/BIO-Lucy_Billingsley.pdf

Sources: tags

COMPANYdate not shown in source

LUCY BILLINGSLEY

Billingsley Company
Lucy started Billingsley Company with her husband, Henry, in 1978
value seen: Founder
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://media.billingsleyco.com/m/142ea9cda897f024/original/BIO-Lucy_Billingsley.pdf

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Partner
https://www.billingsleyco.com/meet-our-team/
HB
Henry Billingsley
Henry Billingsley is a Billingsley partner who previously partnered at Trammell Crow Company and worked at Hayden Stone and Colonial Management. His profile highlights large-scale land acquisition and education at Stanford and Harvard.
Current title
Partner
Experience
no career length stated
Companies before
Trammell Crow CompanyHayden StoneColonial Management
Education
Stanford Universityundergraduate degree
Harvard UniversityMBA
Other boards
Valwood Board
Known for
Partner at Trammell Crow Company
https://www.linkedin.com/in/henry-billingsley-5b98541b

Sources: degree

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
He holds his undergraduate degree from Stanford University and his MBA from Harvard University.
value seen: undergraduate degree
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: institution

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
He holds his undergraduate degree from Stanford University and his MBA from Harvard University.
value seen: Stanford University
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: degree

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
He holds his undergraduate degree from Stanford University and his MBA from Harvard University.
value seen: MBA
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: institution

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
He holds his undergraduate degree from Stanford University and his MBA from Harvard University.
value seen: Harvard University
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Henry Billingsley
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: linkedin page

SOCIALdate not shown in source

Henry Billingsley

LinkedIn
Partner at Billingsley Company
value seen: https://www.linkedin.com/in/henry-billingsley-5b98541b
https://www.linkedin.com/in/henry-billingsley-5b98541b

Sources: other boards

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Henry is a Valwood Board Member.
value seen: Valwood Board
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: previous companies

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Prior to starting Crow/Billingsley, Henry worked as a Partner at the Trammell Crow Company investing in and joint venturing in industrial developments throughout the country.
value seen: Trammell Crow Company
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: previous companies

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Henry also spent years working at Hayden Stone on Wall Street and Colonial Management in Boston.
value seen: Hayden Stone
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: previous companies

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Henry also spent years working at Hayden Stone on Wall Street and Colonial Management in Boston.
value seen: Colonial Management
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Partner
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: summary

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Since the inception of Crow/Billingsley, Henry has purchased over 4,000 acres of land throughout Dallas, Houston and Chicago. Prior to starting Crow/Billingsley, Henry worked as a Partner at the Trammell Crow Company investing in and joint venturing in industrial developments throughout the country.
value seen: Henry Billingsley is a Billingsley partner who previously partnered at Trammell Crow Company and worked at Hayden Stone and Colonial Management. His profile highlights large-scale land acquisition and education at Stanford and Harvard.
held out of the figures · the quote does not carry this value
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: tags

OTHERdate not shown in source

HENRY BILLINGSLEY Partner

Billingsley Company
Prior to starting Crow/Billingsley, Henry worked as a Partner at the Trammell Crow Company investing in and joint venturing in industrial developments throughout the country.
value seen: Partner at Trammell Crow Company
held out of the figures · the quote does not carry this value
https://media.billingsleyco.com/m/3df0c9e17ec5e224/original/BIO-Henry-Billingsley-PDF.pdf

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner
value seen: Partner
https://www.billingsleyco.com/meet-our-team/
LB
Lucy Burns
Lucy Burns is a Billingsley partner responsible for office and single-family portfolios. Before joining the family business, she worked in investment banking, institutional investing and Los Angeles real estate redevelopment.
Current title
Partner - Office
since 2008
Experience
no career length stated
Companies before
The Ratkovich CompanyGroupe ArnaultLehman Brothers
Education
Columbia UniversityMaster’s of Science in Real Estate Development
Davidson CollegeBachelor’s Degree in History
Other boards
Downtown Dallas, Inc.
Known for
ex-Lehman Brothers
https://linkedin.com/in/lucy-burns-27101821

Sources: degree

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Lucy has her Master’s of Science in Real Estate Development from Columbia University and a Bachelor’s Degree in History from Davidson College.
value seen: Master’s of Science in Real Estate Development
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: institution

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Lucy has her Master’s of Science in Real Estate Development from Columbia University and a Bachelor’s Degree in History from Davidson College.
value seen: Columbia University
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: degree

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Lucy has her Master’s of Science in Real Estate Development from Columbia University and a Bachelor’s Degree in History from Davidson College.
value seen: Bachelor’s Degree in History
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: institution

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Lucy has her Master’s of Science in Real Estate Development from Columbia University and a Bachelor’s Degree in History from Davidson College.
value seen: Davidson College
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Office
value seen: Lucy Burns
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: linkedin page

SOCIALdate not shown in source

Lucy Burns

LinkedIn
Partner - Office at Billingsley Company
value seen: https://linkedin.com/in/lucy-burns-27101821
https://linkedin.com/in/lucy-burns-27101821

Sources: other boards

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
She is on the board of directors for Downtown Dallas
value seen: Downtown Dallas, Inc.
held out of the figures · the quote does not carry this value
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: previous companies

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Burns worked for the The Ratkovich Company in Los Angeles, where she managed the renovation of a 500,000 square-foot tower on Wilshire Blvd.
value seen: The Ratkovich Company
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: previous companies

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Before that, she served as head of investments for Groupe Arnault in the U.S., and for Lehman Brothers.
value seen: Groupe Arnault
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: previous companies

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Before that, she served as head of investments for Groupe Arnault in the U.S., and for Lehman Brothers.
value seen: Lehman Brothers
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Office
value seen: Partner - Office
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: since

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
In 2008 Lucy entered the family real estate business, where she manages Billingsley Company’s office and single-family property portfolios.
value seen: 2008
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: summary

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
As a partner with Billingsley Company, Burns currently manages Billingsley Company’s office and single-family property portfolios.
value seen: Lucy Burns is a Billingsley partner responsible for office and single-family portfolios. Before joining the family business, she worked in investment banking, institutional investing and Los Angeles real estate redevelopment.
held out of the figures · the quote does not carry this value
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: tags

PRESS2017-12-15

Women in Real Estate Honoree: Lucy Burns, Partner with Billingsley Company

Connect CRE
Before that, she served as head of investments for Groupe Arnault in the U.S., and for Lehman Brothers.
value seen: ex-Lehman Brothers
held out of the figures · the quote does not carry this value
https://www.connectcre.com/stories/women-real-estate-honoree-lucy-burns-partner-billingsley-company/

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Office
value seen: Partner - Office
https://www.billingsleyco.com/meet-our-team/
GB
George Billingsley
George Billingsley joined Billingsley in multifamily, moved into industrial leasing, and became a partner responsible for portfolio management, development, leasing and financing. His profile records BA and MS management degrees and a Method Bank board seat.
Current title
Partner - Industrial
since 2012
Experience
no career length stated
Companies before
none sourced
Education
Dallas Baptist UniversityBA
Southern Methodist UniversityMaster of Science in Management Degree
Other boards
Method Bank
Known for
nothing tagged
https://linkedin.com/in/george-billingsley-049873123

Sources: degree

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George earned his BA from Dallas Baptist University and his Master of Science in Management Degree from Southern Methodist University
value seen: BA
https://www.showcase.com/p/george-billingsley/5745659/

Sources: institution

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George earned his BA from Dallas Baptist University and his Master of Science in Management Degree from Southern Methodist University
value seen: Dallas Baptist University
https://www.showcase.com/p/george-billingsley/5745659/

Sources: degree

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George earned his BA from Dallas Baptist University and his Master of Science in Management Degree from Southern Methodist University
value seen: Master of Science in Management Degree
https://www.showcase.com/p/george-billingsley/5745659/

Sources: institution

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George earned his BA from Dallas Baptist University and his Master of Science in Management Degree from Southern Methodist University
value seen: Southern Methodist University
https://www.showcase.com/p/george-billingsley/5745659/

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Industrial
value seen: George Billingsley
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: linkedin page

SOCIALdate not shown in source

George Billingsley

LinkedIn
Partner - Industrial at Billingsley Company
value seen: https://linkedin.com/in/george-billingsley-049873123
https://linkedin.com/in/george-billingsley-049873123

Sources: other boards

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
is a member of the board for Method Bank.
value seen: Method Bank
https://www.showcase.com/p/george-billingsley/5745659/

Sources: previous companies

DIRECTORYdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George began his career with Billingsley Company in 2007 as a leasing agent at The Austin Ranch Apartment Development.
value seen: None documented before Billingsley Company
held out of the figures · the quote does not carry this value · the value did not fit the record it was filed under
value paraphrased from this source
https://www.showcase.com/p/george-billingsley/5745659/

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Industrial
value seen: Partner - Industrial
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: since

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George was promoted to Partner in 2012 and now serves in an administrative role in which he is responsible for portfolio management, development, leasing, and financing.
value seen: 2012
https://www.showcase.com/p/george-billingsley/5745659/

Sources: summary

OTHERdate not shown in source

George Billingsley - Commercial Real Estate Listings | Showcase

Showcase
George began his career with Billingsley Company in 2007 as a leasing agent at The Austin Ranch Apartment Development and proceeded to move to the corporate office where he served as multifamily financial analyst and later asset manager.
value seen: George Billingsley joined Billingsley in multifamily, moved into industrial leasing, and became a partner responsible for portfolio management, development, leasing and financing. His profile records BA and MS management degrees and a Method Bank board seat.
held out of the figures · the quote does not carry this value
https://www.showcase.com/p/george-billingsley/5745659/

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Partner - Industrial
value seen: Partner - Industrial
https://www.billingsleyco.com/meet-our-team/
AF
Amanda Flick
Amanda Flick oversees Billingsley’s DFW multifamily communities, lease-ups, stabilized-community performance, centralization and technology adoption. Before Billingsley, she held leadership roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT and Camden Property Trust.
Current title
Senior VP of Multifamily
since Nov 2023 - Present
Experience
25+ years multifamily experience
Companies before
Middleburg CommunitiesIndependence Realty TrustSteadfast REITCamden Property Trust
Education
not published
Other boards
none sourced
Known for
nothing tagged
https://linkedin.com/in/flickamanda

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Senior VP of Multifamily
value seen: Amanda Flick
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: linkedin page

SOCIALdate not shown in source

Amanda Flick

LinkedIn
Senior VP of Multifamily at Billingsley Company
value seen: https://linkedin.com/in/flickamanda
https://linkedin.com/in/flickamanda

Sources: previous companies

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
Before the Billingsley Company, she held leadership and executive roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT, and Camden Property Trust.
value seen: Middleburg Communities
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: previous companies

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
Before the Billingsley Company, she held leadership and executive roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT, and Camden Property Trust.
value seen: Independence Realty Trust
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: previous companies

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
Before the Billingsley Company, she held leadership and executive roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT, and Camden Property Trust.
value seen: Steadfast REIT
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: previous companies

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
Before the Billingsley Company, she held leadership and executive roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT, and Camden Property Trust.
value seen: Camden Property Trust
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Senior VP of Multifamily
value seen: Senior VP of Multifamily
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: since

SOCIALdate not shown in source

Amanda Flick

LinkedIn
SVP of Multifamily at Billingsley Company ... Nov 2023 - Present
value seen: Nov 2023 - Present
https://linkedin.com/in/flickamanda

Sources: summary

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
As the Senior Vice President of Multifamily at Billingsley Company, Amanda oversees a portfolio of beautifully designed, life-enhancing communities in the DFW surrounding areas, where she focuses on new community lease-ups, maximized performance of stabilized communities, centralization efforts, and the adoption of technology solutions that streamline processes and elevate customer service.
value seen: Amanda Flick oversees Billingsley’s DFW multifamily communities, lease-ups, stabilized-community performance, centralization and technology adoption. Before Billingsley, she held leadership roles at Middleburg Communities, Independence Realty Trust, Steadfast REIT and Camden Property Trust.
held out of the figures · the quote does not carry this value
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: tags

OTHERdate not shown in source

What Happens When AI Joins the Onsite Team | Realpage

RealPage
With over 25 years of experience in property management operations, sales, marketing, customer service, and technology implementation
value seen: 25+ years multifamily experience
held out of the figures · the quote does not carry this value
https://www.realpage.com/webcasts/ai-joins-onsite-team/

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
Senior VP of Multifamily
value seen: Senior VP of Multifamily
https://www.billingsleyco.com/meet-our-team/
LP
Lucilo Peña
Lucilo Peña is Billingsley’s president of development and an architect. He has held senior civic and cultural leadership roles, including trustee and vice president of the Dallas Museum of Art.
Current title
President of Development
Experience
no career length stated
Companies before
none sourced
Education
not published
Other boards
Dallas Museum of ArtDallas Architectural ForumHuman Rights Campaign
Known for
Architect

Sources: full name

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
President of Development
value seen: Lucilo Peña
held out of the figures · the quote does not carry this value
https://www.billingsleyco.com/meet-our-team/

Sources: other boards

OTHER2026-08-13

Lucilo Pena and Lee Cobb

PatronView
He has served as a trustee and vice president of the Dallas Museum of Art
value seen: Dallas Museum of Art
https://patronview.com/patrons/lucilo-pena-and-lee-cobb

Sources: other boards

OTHER2026-08-13

Lucilo Pena and Lee Cobb

PatronView
a director of the Dallas Architectural Forum
value seen: Dallas Architectural Forum
https://patronview.com/patrons/lucilo-pena-and-lee-cobb

Sources: other boards

OTHER2026-08-13

Lucilo Pena and Lee Cobb

PatronView
a board member of the Human Rights Campaign.
value seen: Human Rights Campaign
https://patronview.com/patrons/lucilo-pena-and-lee-cobb

Sources: role type

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
President of Development
value seen: President of Development
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.billingsleyco.com/meet-our-team/

Sources: summary

OTHER2026-08-13

Lucilo Pena and Lee Cobb

PatronView
Lucilo Peña is an architect and the president of development at the Billingsley Company in Dallas. He has served as a trustee and vice president of the Dallas Museum of Art, a director of the Dallas Architectural Forum, and a board member of the Human Rights Campaign.
value seen: Lucilo Peña is Billingsley’s president of development and an architect. He has held senior civic and cultural leadership roles, including trustee and vice president of the Dallas Museum of Art.
held out of the figures · the quote does not carry this value
https://patronview.com/patrons/lucilo-pena-and-lee-cobb

Sources: tags

OTHER2026-08-13

Lucilo Pena and Lee Cobb

PatronView
Lucilo Peña is an architect and the president of development at the Billingsley Company in Dallas.
value seen: Architect
https://patronview.com/patrons/lucilo-pena-and-lee-cobb

Sources: title

COMPANYdate not shown in source

Meet Our Team – Billingsley Company

Billingsley Company
President of Development
value seen: President of Development
https://www.billingsleyco.com/meet-our-team/

Projects

Assessment coverage

Completed projects: 2016-10-15 through 2026-10-15. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases
The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

10 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
August HillsDallas, United States
Valley Ranch
residential for rent5411———————Jan 2025 – Dec 2025—not scorablecompleted
Denton Distribution CenterDenton, United States
industrial——900,000 sq ftUSD 40m
estimated cost
———Jan 2023 – Dec 2023Jan 2024 – Dec 2024+12.0 mo
(+1.0 to +23.0)
sourcedcompleted
The BeaconPlano, United States
Beacon Square
residential for rent53914——————Jan 2024 – Dec 2024—not scorablecompleted
The ChloeThe Colony, United States
residential for rent41814——————Jan 2024 – Dec 2024—not scorablecompleted
3300 Olympus BoulevardCoppell, United States
Cypress Waters
office—6303,250 sq ft——20212021Jan 2023 – Dec 2023Jun 2023−0.5 mo
(−6.0 to +5.0)
sourcedcompleted
At Home HeadquartersCoppell, United States
Cypress Waters
office—4180,000 sq ft——2022January 11, 2022Dec 2022Jun 2023+6.0 mo
(+6.0 to +6.0)
sourcedcompleted
International Business Park 18Plano, United States
International Business Park
office—5242,000 sq ft——20212021Mar 2023Feb 2023dates under reviewdates under reviewcompleted
Hastings EndDallas, United States
Cypress Waters
residential for rent499151,318 sq ft————Jan 2023 – Dec 2023Jan 2023 – Dec 20230.0 mo
(−11.0 to +11.0)
sourcedcompleted
Wylder SquareCarrollton, United States
residential for rent3721————202103/01/2021Jan 2023Jan 2022 – Dec 2022−6.5 mo
(−12.0 to −1.0)
sourcedcompleted
Sage Hill at Cypress WatersCoppell, United States
Coppell School District
residential for rent3831————2019December 2019—Jan 2021 – Dec 2021—not scorablecompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

6 found
COMPANY AWARD Winner March 9, 2023
Dallas Business Journal Lifetime Achievement Award
Lucy Billingsley of Billingsley Company was selected as the 2023 Lifetime Achievement Award winner.
PROJECT AWARD Winner May 23, 2024 (award presented earlier that month)
TEXO Distinguished Building Award · Building 18, International Business Park
Building 18 of Billingsley Company’s International Business Park was named a 2024 Distinguished Building Award winner.
RANKING Ranked November 12, 2020
Top 100 Places to Work
Billingsley Company was listed as a first-time winner at No. 24 among midsize companies in the 2020 ranking.
RANKING Ranked 2018
NMHC Top 25 Builders
Billingsley Company was listed among the NMHC Top 25 Builders.
National Multifamily Housing Council · https://www.billingsleyco.com/our-expertise/
COMPANY AWARD Winner 2019
Developer of the Year
The developer reports that Lucy Billingsley and Billingsley Company received a Developer of the Year recognition.
PROJECT AWARD Winner 2020
Best Multi-family Project · The Neighborhoods at The Sound
The Neighborhoods at The Sound received the Dallas Business Journal Awards’ Best Multi-family Project recognition.
Dallas Business Journal Awards · https://www.billingsleyco.com/our-expertise/

Risks

Risk flags

2 found
LEGAL Filed November 10, 2023; settled February 24, 2025; dismissed with prejudice March 5, 2025
A former marketing director sued Billingsley Property Services II, Inc., d/b/a The Billingsley Company, alleging disability discrimination, interference and retaliation under the FMLA, and ERISA-related discrimination after her November 14, 2022 termination; Billingsley denied the allegations, and the case was settled and dismissed with prejudice on March 5, 2025, without a merits finding.
RISK Complaints reported May 2025, May 2024, July 2024, January 2024 and earlier; BBB page current as of 2026
BBB records reported multiple resident billing and move-out disputes involving Billingsley-managed properties, including allegations of incorrect rent or security-deposit charges, unexplained cleaning or accelerated-rent charges, and delayed refunds; the records also show several company responses and some resolved complaints, so these are consumer allegations rather than adjudicated findings.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 11, 2026 this month
Profile last researchedOctober 11, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.