Artificial Intelligence
Builders Company
Developers/Lonestar Development Partners
LD
Lonestar Development PartnersAustin, United States · founded 2015 · 1 active markets
PRIVATE

Lonestar Development Partners develops multifamily housing in Central Texas, including mixed-use urban infill, single-family rental communities, garden-style apartments, and suburban townhome or condominium projects. Its residents include renters and homebuyers, while investors and public-sector partners support delivery across Texas today.

Years in business
11
founded 2015
LinkedIn headcount
12 people
employees, as shown on LinkedIn · size band 11–50
Portfolio value
USD 750 million
as the company states it
Total projects
10 projects
across the company’s whole history
Units delivered
1,400+ new homes
as the company states it
Projects last researched October 16, 2026
Every figure on this card was read out of a document.

Overview

Investor tear sheet

a summary of the tabs that follow · no rating of our own

Company dossier

Legal name
not published
Headquarters
8121 Bee Caves Road1, Austin1, United States
Founded
20151
Entity type
PRIVATE1
Business model
offplan for sale1, build to rent1, commercial1, mixed use1, masterplan1
Markets
1 market listed
What they build
Residential, for rent (4 of 5) · Residential, for sale (1 of 5)
Full dossier in About →

Delivery record

2 date-assessed of 5 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-16 through 2026-10-16, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
5
within the rolling ten-year window
Median delay
+35.0 mo
the middle of 2 scored projects
Average delay
+35.0 mo
the same projects, pulled by the worst
Average time to deliver
—
2 delivered projects with a dated start — needs 3
Worst slip
+41.5 mo
The Landing at Lakeway · +36.0 to +47.0
0
early or less than 6 months late
6 to 12 months late
0
yellow rows below
Over 12 months late
2
red rows below

Against other developers

2 date-assessed projects here
Not enough info yet.
Projects and timelines in Track Record →

Resident experience

5 of 5 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
7.2/ 10
Weighted judgment across build and operations · from 5 of 5 rated buildings
Structure & systems
5.3/ 10
Fabric, services, waterproofing, envelope · from 3 of 5 rated buildings
Management & living
6.3/ 10
Upkeep, response times, amenities, community · from 4 of 5 rated buildings

Against other developers

5 rated here · 309 developers, 1550 rated buildings in United States
Overall rating
Lonestar Development Partners · 309 other developers in United States
7.2 vs 7.8
this developer 0.6 worse
The weighted verdict on each side. From 5 of 5 rated buildings here and 1550 in the market.
Structure & systems
Lonestar Development Partners · 309 other developers in United States
5.3 vs 6.9
this developer 1.6 worse
Fabric and engineering only — fixed at handover. From 3 of 5 rated buildings here and 672 in the market.
Management & living
Lonestar Development Partners · 309 other developers in United States
6.3 vs 7.4
this developer 1.1 worse
Upkeep and response — belongs to whoever runs the building now. From 4 of 5 rated buildings here and 1492 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.
Ratings by building →

Awards & recognition

  • RANKING Ranked May 12, 2020 (reported by the developer); list published May 8, 2020
    Austin-area multifamily real estate development firms — The List
    The developer reports that Lonestar Development Partners ranked No. 6 on Austin Business Journal’s list of Austin-area multifamily development firms, based on units under construction; this is a 2020 publication and does not establish a current 2026 ranking.
All awards →

Risks & source coverage

  • LEGAL Filed April 3, 2026; docket information current through May 18, 2026 A commercial-and-trade contract lawsuit was filed against Lone Star PE, LLC, which is identified in the court docket as doing business as Lonestar Development Partners, and Christopher Kopacek; the defendants filed a general denial, and the case was still open in the retrieved docket information.
  • DELIVERY DELAY Buyer review dated July 25, 2022; page retrieved September 14, 2026 A buyer review alleged that a townhome at The Landing at Lakeway took years to build and complained of poor craftsmanship, low quality, and that Lonestar Development Partners had not made things right; this is an unverified customer allegation, not a formal finding.
  • DELIVERY DELAY 2023-12-20 publication; Spring 2026 projected opening; 2026-10-16 research position Presidio Apartments, a San Antonio project reported as being developed by Lonestar Development Partners, appears overdue: a December 2023 report projected a Spring 2026 opening, while the state project record lists completion for October 1, 2028 and a related commercial building permit remained pending issuance on October 8, 2026; this documents delayed delivery, not abandonment.
Record status
active
Company sources
105 source entries across 105 fields
Projects tracked
5 · 5 completed in assessment
All flags and sources →

Track Record

Delivery record

2 date-assessed of 5 projects
Unverified by developer

AI-researched delivery record, not yet confirmed by the developer. Dates may be approximate; original sources are linked.

Completed projects from 2016-10-16 through 2026-10-16, with sufficient delivery-date evidence. Date assessment and developer profile verification do not mean an independent audit of every source. Original source links and available snippets are provided. May not represent the developer’s full portfolio. 0 undated and 0 boundary-uncertain completions are excluded. Delivery exceptions are listed separately under Projects.
Completed projects assessed
5
within the rolling ten-year window
Median delay
+35.0 mo
the middle of 2 scored projects
Average delay
+35.0 mo
the same projects, pulled by the worst
Average time to deliver
—
2 delivered projects with a dated start — needs 3
Worst slip
+41.5 mo
The Landing at Lakeway · +36.0 to +47.0
0
early or less than 6 months late
6 to 12 months late
0
yellow rows below
Over 12 months late
2
red rows below

Against other developers

2 date-assessed projects here
Not enough info yet.

Construction start to handover

5 of 5 projects dated · 4 places
Based on covered projects with documented construction or launch dates and available handover dates. Timelines vary by project and may not represent the developer’s full portfolio.
Construction start, or the launchTarget completion (window)Completion or handover, as reportedCurrently statedLaunch year only, no date publishedEarly or ≤6 mo lateOver 6–12 mo lateOver 12 mo lateStalled
Lakeway, United States
Austin, United States
Leander, United States
Pflugerville, United States
201620172018201920202021202220232024202520262027todayLAKEWAY, UNITED STATES+41.5 moverifiedAUSTIN, UNITED STATES+7.5 moestimated+28.5 moverifiedLEANDER, UNITED STATEScompleted, no target publishedPFLUGERVILLE, UNITED STATEScompleted, no target published
Click a row in the chart to open a project, or a table row below to see its sources. The chart runs wider than the page where the record spans many years — scroll it sideways to follow a project to its handover. Every date we have is drawn. A hollow marker is only a launch year, not a date anyone published. No dates published means we looked and found none; dates not yet checked means we have not looked yet. Handing over is not finished — rows say which. A delay is shown when one source gives the promised date and another gives the real one, however rough: "2019" still counts, and the row shows how wide that is. Projects missing one of the two dates, or with sources that disagree, are left out of the figures.

Building & Livability Ratings

Resident experience

5 of 5 buildings rated · scale 1–10

AI research over published reviews and resident comments. Scores are a model’s reading of opinion, not figures stated on a page, and nothing here feeds any number above it. The links under each block are the pages that research says it used. Based on available resident reviews of covered buildings. These are reported experiences, not independent building inspections, and may not represent all residents or properties.

Overall verdict
7.2/ 10
Weighted judgment across build and operations · from 5 of 5 rated buildings
Structure & systems
5.3/ 10
Fabric, services, waterproofing, envelope · from 3 of 5 rated buildings
Management & living
6.3/ 10
Upkeep, response times, amenities, community · from 4 of 5 rated buildings

Against other developers

5 rated here · 309 developers, 1550 rated buildings in United States
Overall rating
Lonestar Development Partners · 309 other developers in United States
7.2 vs 7.8
this developer 0.6 worse
The weighted verdict on each side. From 5 of 5 rated buildings here and 1550 in the market.
Structure & systems
Lonestar Development Partners · 309 other developers in United States
5.3 vs 6.9
this developer 1.6 worse
Fabric and engineering only — fixed at handover. From 3 of 5 rated buildings here and 672 in the market.
Management & living
Lonestar Development Partners · 309 other developers in United States
6.3 vs 7.4
this developer 1.1 worse
Upkeep and response — belongs to whoever runs the building now. From 4 of 5 rated buildings here and 1492 in the market.
The market here is United States: every other developer whose head office is in the same country, because the review platforms residents use, and the service norms they judge against, move together within one. It is not a city, a sector or a price band. Read structure and living together. A developer above the market on structure and below it on living builds well and runs buildings badly, which is a fixable problem and a different one from building badly. Higher ratings are better; differences use the displayed scores rounded to one decimal. Rated buildings only, on both sides, and a structure or living score with no stated basis — no review count and no notes or links — is left out of both.

By building

5 rated · 0 not rated · scale 1–10
ProjectOverallStructure & systemsManagement & living
Walden SquarePflugerville82 units
8.0/ 10
5.3/ 10
RentCafe 3/5 · 5 reviews · rentcafe.com
RentCafe publishes 3/5 from 5 reviews. Adjusted for where resident ratings usually fall, and weighted toward the 6.5 midpoint (more strongly the fewer the reviews), that gives 5.3.
6.4/ 10
RentCafe 4.5/5, 3/5, 3/5, 3.5/5, 4.5/5, 4/5 · 5 reviews · rentcafe.com
Combined from 6 published figures on 1 platform, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 6.4.

Google’s 4.4/5 rating from 72 reviews sets the level and converts to 8.2 under the supplied curve. Repeated praise for Faith, community events and the peaceful setting supports daily living, but recurring reports of maintenance delays, turnover and communication problems pull the overall result down to 8.0; structure is separately constrained by the 3.0/5 maintenance evidence and the reported electrical/A/C failures.

+ Modern construction+ Energy-efficient features+ Central air and heating+ Well-kept homes and grounds
− Faulty electrical breakers reported− Broken A/C reported− Maintenance delays− Unresolved unit defects
+ Helpful property manager+ Friendly staff+ Monthly community events+ Peaceful setting+ Private yards and garages
− Management turnover− Communication complaints− Maintenance follow-up burden− Limited shared amenities− Car-dependent location

RentCafe publishes a 3.0/5 maintenance sub-rating from five reviews. One July 2022 resident reported “faulty electrical breakers for over half our lease” and a “broken A/C for almost the entire lease,” while also saying some defects remained unaddressed; these are old reports, and the later review material describes improved responsiveness under newer management.

Recent review material is strongly positive about Faith, with more than 20 Google-review mentions and praise that she is “patient” and goes “out of her way to help”; another resident said management events “make it worth living here.” The older RentCafe record is materially harsher, including “4 property managers” in one year and advice that for maintenance “you’re better off paying for it yourself”; the available evidence suggests improvement, but the strongest positive evidence is recent and tied to one manager.

Bee Caves VistasOak Hill, Austin89 units
7.7/ 10
6.0/ 10
RentCafe 3.5/5 · 5 reviews · rentcafe.com
RentCafe publishes 3.5/5 from 5 reviews. Adjusted for where resident ratings usually fall, and weighted toward the 6.5 midpoint (more strongly the fewer the reviews), that gives 6.
6.5/ 10
RentCafe 3/5, 2/5, 4/5, 4/5, 4/5, 4.5/5, 4.5/5 · 5 reviews · rentcafe.com
Combined from 7 published figures on 1 platform, weighted by review count, adjusted for where resident ratings usually fall and weighted toward the 6.5 midpoint where reviews are few: 6.5.

Apartments.com supplies the largest qualifying review base: 4.2/5 from 21 renter reviews, converted to approximately 7.6/10 under the stated curve. The written feedback is strongly positive on management, maintenance, quietness, safety, views and space, with modest deductions for limited communal amenities and cheap appliances/cabinetry; no second platform with at least 10 reviews provides a material scored disagreement. Evidence is review-based through October 16, 2026; some favorable Apartments.com reviews are older, while RentCafe includes reviews dated in 2026.

+ Well-maintained homes+ Spacious modern layouts+ Hill-country views+ Attached garages+ Quiet buildings
− Cheap appliances− Cheap cabinetry/build-out
+ Quick maintenance response+ Helpful management+ Friendly neighbors+ Quiet and safe+ Scenic views
− Limited amenities− Few communal gathering spaces− No pool− High rent/value concern

Residents generally describe the homes as modern, spacious and well maintained, with one calling the townhomes “well maintained and quiet” and another saying the property was “well maintained.” The main physical criticism was that “the appliances are cheap” and the cabinets and other build-out were “on the cheap side”; no published review evidence located here establishes flooding, major leaks, HVAC failure or other severe system failure.

Daily-life feedback is mostly favorable: residents call maintenance “quick and helpful,” describe staff as “excellent and helpful,” and praise a “quiet and safe” community with friendly neighbors. The repeated drawback is amenity depth: reviewers mention no pool, limited communal space and “not huge on amenities,” while one Apartment List reviewer said there were “no amenities to speak of” beyond dog-related facilities.

The Landing at LakewayLakeway75 units
7.4/ 10
—/ 10
—/ 10

The only located published aggregate is Yelp’s 5/5 based on one review, which cannot be used as an anchor under the stated rule requiring at least 10 reviews. The evidence also falls below the three-review minimum for prose-only scoring, so no numerical score is assigned; the available review evidence is old (published in 2022) and should not be treated as a current 2026 assessment.

+ Well-built community
+ Recommended by reviewer

The only building-condition comment located was positive: the reviewer described the community as “well built.” No published review evidence was found regarding plumbing, HVAC, electrical systems, leaks, waterproofing, or other physical-system failures.

The single review describes The Landing as a “Fantastic” condo community and says, “I would highly recommend” it for someone wanting a three-bedroom condo in Lakeway. It does not provide evidence about management response times, staff, security, cleanliness, or common-area upkeep.

The Rail at MLKAustin235 units
7.1/ 10
—/ 10
6.9/ 10

The Google aggregate of 4.3/5 from 152 reviews sets the level and converts to 7.0/10. The written feedback is strongly positive about staff, maintenance, cleanliness and location, but the reported noise, package/maintenance issues and one access/key-fob outage reduce confidence in an unadjusted anchor score.

+ Helpful staff+ Responsive management+ Fast maintenance+ Clean pool and common areas+ Good transit access
− Thin-wall noise− Package-delivery issues− Some maintenance delays− Door/key-fob outages

no notes returned

no links returned

Published reviews frequently praise staff and management: residents called the team “helpful,” “responsive,” and said maintenance fixed issues “within less than 2 days.” The same review summaries mention thin walls, occasional package-delivery and maintenance responsiveness problems, while one review reported “doors inaccessible” and key-fob outages, albeit with fast management communication.

Trailside OaksLeander105 units
6.0/ 10
4.5/ 10
5.5/ 10

The largest published review aggregate located was Google’s 3.3/5 from 102 reviews, which converts to a 7.0 anchor under the specified curve. The written reviews were predominantly negative and included several serious operational or systems reports, so the score is reduced by the maximum 1.0-point commentary adjustment; the 3.4/5 listing from 99 reviews is materially consistent and does not create a dissent.

− Elevator breakdowns− HVAC/heating failure− Reported AC and appliance fire concerns
+ Spacious and modern townhomes+ Greenery and open space
− Management instability− Delayed or unresponsive management− Shared-area trash and cleanliness− Parking-space conflicts− Security/access concerns

Published reviews include reports that “the elevator breaks down regularly” and that one resident was living in a home that was “44 degrees” during a winter storm. Another review reports that AC units and stoves were said to have caught fire, but that allegation is unverified and is reported here only as resident feedback, not as an established fact.

The available reviews describe a difficult day-to-day experience: one resident said management teams changed “every couple of months,” while another reported that trash remained in hallways and stairwells for days. The sole clearly positive review praised “very spacious and modern” townhomes and the greenery, but the reviewed sample was otherwise strongly negative.

Only buildings that have reached handover are rated. 0 of 5 projects carry no rating: a building still under construction is never asked about, one that has just been handed over may not have been reached yet, and the rest were asked about and no published resident commentary was found. Structure is fixed at handover and stays the developer's; management and living belongs to whoever runs the building now. The overall verdict weights both rather than averaging them. None of this is checked: a rating is what people published about a building, aggregated — it is not evidence, it cannot move a delay figure, and it is not part of the delivery record above.

About

Company dossier

Legal name
not published
Headquarters
8121 Bee Caves Road, Austin, United States
78746
Founded
2015
Austin, United States
Entity type
PRIVATE
Revenue
not published
Business model
offplan for sale, build to rent, commercial, mixed use, masterplan

Partners

4 partners
Housing Authority of the City of Austin
government partner

HACA partnered with LDP and LDG on The Rail at MLK, a mixed-income apartment project.

LDG Development
joint venture

LDG partnered with LDP and HACA on The Rail at MLK, including its affordable and mixed-income housing delivery.

Mason Joseph Inc.
funder

Mason Joseph helped secure the loan for The Rail at MLK through HUD’s 221(d)(4) program.

U.S. Department of Housing and Urban Development
government partner

HUD’s 221(d)(4) program was the financing program used for The Rail at MLK loan.

Sources: name

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
HACA and its partners Austin-based multifamily developer Lonestar Development Partners (LDP) and LDG Development recently broke ground on The Rail at MLK, a 235-unit mixed-income apartment building located at 2921 E. 17th St.
value seen: HACA
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: partner type

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
“HACA’s subsidiary, theAustin Affordable Housing Corporation, is extremely excited to partner with LDP and LDG on The Rail at MLK,” said HACA President and CEO Michael Gerber.
value seen: HACA ... partner
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: summary

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
“HACA’s subsidiary, theAustin Affordable Housing Corporation, is extremely excited to partner with LDP and LDG on The Rail at MLK,” said HACA President and CEO Michael Gerber.
value seen: partnered with LDP and LDG on The Rail at MLK
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: name

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
HACA and its partners Austin-based multifamily developer Lonestar Development Partners (LDP) and LDG Development recently broke ground on The Rail at MLK, a 235-unit mixed-income apartment building located at 2921 E. 17th St.
value seen: LDG Development
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: partner type

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
“HACA’s subsidiary, theAustin Affordable Housing Corporation, is extremely excited to partner with LDP and LDG on The Rail at MLK,” said HACA President and CEO Michael Gerber.
value seen: partner with LDP and LDG
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: summary

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
“HACA’s subsidiary, theAustin Affordable Housing Corporation, is extremely excited to partner with LDP and LDG on The Rail at MLK,” said HACA President and CEO Michael Gerber.
value seen: partner with LDP and LDG on The Rail at MLK
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: name

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: Mason Joseph Inc.
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: partner type

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: help ... secured the loan
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: summary

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: Mason Joseph Inc. ... loan ... HUD’s 221(d)(4) program
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: name

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: HUD
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: partner type

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: HUD’s 221(d)(4) program
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Sources: summary

PRESS2018-12-14

The Rail at MLK Brings Affordability Mix to East Austin

Housing Authority City Of Austin · carried by hacanet.org
The loan was secured with the help of Mason Joseph Inc., through HUD’s 221(d)(4) program.
value seen: HUD’s 221(d)(4) program ... The Rail at MLK
held out of the figures · the quote does not carry this value
value paraphrased from this source
https://www.hacanet.org/award-accomplishment/the-rail-at-mlk-brings-affordability-mix-to-east-austin/

Registrations & licences

none found
Jurisdiction-agnostic: a DLD number, a Companies House number and a state RERA registration all land in the same table.

Contact

Markets

1 countries
United Statesactive 5 projects tracked

What they build

2 types
Residential, for rent4 of 5
Residential, for sale1 of 5
A project counts once under each type it carries, so the shares add to more than the project count.

Management

Principals & executives

6 names found
RL
Ryan Larson
Ryan Larson co-founded LDP and leads overall strategy, development, acquisitions, and construction operations. Independent reporting describes him as a former martial-arts fighter who co-founded the Austin developer with Chris Kopacek in 2015 and pursued attainable rental housing.
Current title
Co-Founder & Managing Partner
Experience
no career length stated
Companies before
none sourced
Education
University of Texas at AustinMBA
Other boards
none sourced
Known for
Co-FounderManaging Partner2015 co-founderAustin real estate
since Since co-founding LDP in 2015
We met a lot of folks and we got a lot of no’s,” Larson said. “But we finally got a breakthrough with Bee Caves Vista. austinrealestatenews.org July 8, 2018https://austinrealestatenewsorg.wordpress.com/2018/07/08/fighter-pilot-martial-arts-bruiser-punch-out-new-real-estate-concept/

Sources: education

PRESS2018-07-08

Fighter pilot, martial arts bruiser punch out new real estate concept

austinrealestatenews.org
They met as students in the MBA program at the University of Texas.
value seen: University of Texas at Austin; MBA
held out of the figures · the quote does not carry this value
https://austinrealestatenewsorg.wordpress.com/2018/07/08/fighter-pilot-martial-arts-bruiser-punch-out-new-real-estate-concept/

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Ryan Larson
value seen: Ryan Larson
https://ldpre.com/

Sources: quote

PRESS2018-07-08

Fighter pilot, martial arts bruiser punch out new real estate concept

austinrealestatenews.org
“We met a lot of folks and we got a lot of no’s,” Larson said. “But we finally got a breakthrough with Bee Caves Vista.”
value seen: We met a lot of folks and we got a lot of no’s,” Larson said. “But we finally got a breakthrough with Bee Caves Vista.
https://austinrealestatenewsorg.wordpress.com/2018/07/08/fighter-pilot-martial-arts-bruiser-punch-out-new-real-estate-concept/

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder & Managing Partner
value seen: Co-Founder & Managing Partner
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Since co-founding LDP in 2015
value seen: Since co-founding LDP in 2015
https://ldpre.com/

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder and Managing Partner of Lonestar Development Partners. Leads overall strategy, development, acquisitions, and construction operations.
value seen: co-founded LDP and leads overall strategy, development, acquisitions, and construction operations
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

PRESS2018-07-08

Fighter pilot, martial arts bruiser punch out new real estate concept

austinrealestatenews.org
The fighter — Ryan Larson — and pilot — Chris Kopacek — founded Lonestar Development Partners in Austin in 2015
value seen: Co-Founder; Managing Partner; 2015 co-founder; Austin real estate
https://austinrealestatenewsorg.wordpress.com/2018/07/08/fighter-pilot-martial-arts-bruiser-punch-out-new-real-estate-concept/

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder & Managing Partner
value seen: Co-Founder & Managing Partner
https://ldpre.com/
CK
Chris Kopacek
Chris Kopacek co-founded LDP and leads business development, capital markets, investor relations, and strategic partnerships. His public profile says he runs capital-markets initiatives and the co-GP pipeline; before LDP he worked in water, distressed-debt real estate, and served as an Air Force F-16 pilot.
Current title
Co-Founder & Principal
since Jun 2015 - Present
Experience
no career length stated
Companies before
Invictus WaterMBR Water SolutionsM2 Capital Real EstateUnited States Air Force
Education
Texas McCombs School of Business, University of Texas at AustinMBA Business
United States Air Force AcademyBachelor of Science, Business Administration and Management
Other boards
none sourced
Known for
Co-FounderPrincipalCapital marketsInvestor relationsMBA
https://www.linkedin.com/in/chris-kopacek-5a2aa931

Sources: education

SOCIALdate not shown in source

Chris Kopacek

LinkedIn
### MBA Business at Texas McCombs School of Business ... ### Bachelor of Science (B.S.) Business Administration and Management General at United States Air Force Academy
value seen: Texas McCombs School of Business, University of Texas at Austin — MBA Business; United States Air Force Academy — Bachelor of Science, Business Administration and Management
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/chris-kopacek-5a2aa931

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
## Chris Kopacek
value seen: Chris Kopacek
https://ldpre.com/

Sources: linkedin page

SOCIALdate not shown in source

Chris Kopacek

LinkedIn · carried by ldpre.com
https://www.linkedin.com/in/chris-kopacek-5a2aa931
value seen: https://www.linkedin.com/in/chris-kopacek-5a2aa931
https://ldpre.com/

Sources: previous companies

SOCIALdate not shown in source

Chris Kopacek

LinkedIn
### President - [Invictus Water] ... ### CFO / Senior Account Executive - MBR Water Solutions ... ### Senior Associate -Distressed Debt - [M2 Capital Real Estate] ... ### F-16 Pilot / Instructor Pilot - [United States Air Force]
value seen: Invictus Water; MBR Water Solutions; M2 Capital Real Estate; United States Air Force
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/chris-kopacek-5a2aa931

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder & Principal
value seen: Co-Founder & Principal
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

SOCIALdate not shown in source

Chris Kopacek

LinkedIn
Jun 2015 - Present (11 years and 4 months) in Austin, Texas, United States
value seen: Jun 2015 - Present
https://www.linkedin.com/in/chris-kopacek-5a2aa931

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder and Principal of Lonestar Development Partners. Leads business development, capital markets, investor relations, and strategic partnerships.
value seen: co-founded LDP and leads business development, capital markets, investor relations, and strategic partnerships
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

SOCIALdate not shown in source

Chris Kopacek

LinkedIn
Founding Partner at Lonestar Development Partners. Lonestar has completed over $320Mil of multifamily development project and currently has 6 ground up projects totaling over $300Mil
value seen: Co-Founder; Principal; Capital markets; Investor relations; MBA; F-16 pilot
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/chris-kopacek-5a2aa931

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Co-Founder & Principal
value seen: Co-Founder & Principal
https://ldpre.com/
BW
Brad Walters
Brad Walters is LDP’s development lead, responsible for sourcing and executing new opportunities. His résumé records multifamily development leadership at LDP, Aspen Heights, Forestar Group, Trammell Crow Residential, and Carmel Partners, including large rental-community and development-budget track records.
Current title
Director of Development
Experience
no career length stated
Companies before
Aspen HeightsForestar GroupTrammell Crow ResidentialCarmel PartnersBrightwork PartnersDoughnetWells Fargo BankCredit Suisse First Boston
Education
New York UniversityMBA, Finance and Accounting
University of Southern CaliforniaBachelor of Arts, Humanities
Other boards
none sourced
Known for
Director of DevelopmentMultifamily developmentMBACFA17 rental communities
2020 to Present

Sources: education

OTHERdate not shown in source

Brad Walters

public meeting attachment
MBA, Finance and Accounting, New York University ... Bachelor of Arts, Humanities, University of Southern California
value seen: New York University — MBA, Finance and Accounting; University of Southern California — Bachelor of Arts, Humanities
held out of the figures · the quote does not carry this value
https://mccmeetingspublic.blob.core.usgovcloudapi.net/rollwdtx-meet-815e74cdf252429ca21bc7a5b2ef71e6/ITEM-Attachment-001-2dd4028c32ee4d4a8da1cd808d903ab0.pdf

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Brad Walters
value seen: Brad Walters
https://ldpre.com/

Sources: previous companies

OTHERdate not shown in source

Brad Walters

public meeting attachment
ASPEN HEIGHTS • Austin, TX VP, Multifamily Development 2016 to 2019 ... FORESTAR GROUP ... TRAMMELL CROW RESIDENTIAL ... CARMEL PARTNERS ... BRIGHTWORK PARTNERS ... DOUGHNET ... WELLS FARGO BANK ... CREDIT SUISSE FIRST BOSTON
value seen: Aspen Heights; Forestar Group; Trammell Crow Residential; Carmel Partners; Brightwork Partners; Doughnet; Wells Fargo Bank; Credit Suisse First Boston
held out of the figures · the quote does not carry this value
https://mccmeetingspublic.blob.core.usgovcloudapi.net/rollwdtx-meet-815e74cdf252429ca21bc7a5b2ef71e6/ITEM-Attachment-001-2dd4028c32ee4d4a8da1cd808d903ab0.pdf

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Director of Development
value seen: Director of Development
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

OTHERdate not shown in source

Brad Walters

public meeting attachment
LONESTAR DEVELOPMENT PARTNERS • Austin, TX Managing Director 2020 to Present
value seen: 2020 to Present
held out of the figures · the value did not fit the record it was filed under
https://mccmeetingspublic.blob.core.usgovcloudapi.net/rollwdtx-meet-815e74cdf252429ca21bc7a5b2ef71e6/ITEM-Attachment-001-2dd4028c32ee4d4a8da1cd808d903ab0.pdf

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Responsible for sourcing and executing all new development opportunities.
value seen: LDP’s development lead, responsible for sourcing and executing new opportunities
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Managed development of 17 rental communities with capitalization exceeding $850 million.
value seen: Director of Development; Multifamily development; MBA; CFA; 17 rental communities
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Brad Walters Director of Development
value seen: Director of Development
https://ldpre.com/
JS
Jeff Slocum
Jeff Slocum directs LDP’s in-house construction function. The company describes a 35-year multifamily and mixed-use construction background and more than 10,000 units built, while his professional profile documents prior senior construction roles at Bonner Carrington, Simpson Housing, American Campus Communities, and others.
Current title
Director of Construction
Experience
35+ years real estate
Companies before
Bonner CarringtonSimpson HousingAlliance Residential
Education
not published
Other boards
none sourced
Known for
Director of Construction10,000+ units$1.5B construction
Jun 2021 - Present
since https://www.linkedin.com/in/jeff-slocum-43b606a

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Jeff Slocum
value seen: Jeff Slocum
https://ldpre.com/

Sources: linkedin page

SOCIALdate not shown in source

Jeff Slocum

LinkedIn · carried by ldpre.com
https://www.linkedin.com/in/jeff-slocum-43b606a
value seen: https://www.linkedin.com/in/jeff-slocum-43b606a
https://ldpre.com/

Sources: previous companies

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Previously held vice president roles with Bonner Carrington, Simpson Housing, and Alliance Residential.
value seen: Bonner Carrington; Simpson Housing; Alliance Residential
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Director of Construction
value seen: Director of Construction
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

SOCIALdate not shown in source

Jeff Slocum

LinkedIn
Director Of Construction - [Lonestar Development Partners] (Current) Jun 2021 - Present
value seen: Jun 2021 - Present
https://www.linkedin.com/in/jeff-slocum-43b606a

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Directs in-house construction.
value seen: directs LDP’s in-house construction function
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Built more than 10,000 units, exceeding $1.5 billion in new construction.
value seen: Director of Construction; 35 years real estate; 10,000+ units; $1.5B construction
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Jeff Slocum Director of Construction
value seen: Director of Construction
https://ldpre.com/
CW
Chris White
Chris White coordinates LDP’s capital-markets activities. The company says he joined from The Amherst Group and has more than 20 years’ experience spanning finance, private equity, and real estate.
Current title
Director of Capital Markets
Experience
20+ years finance
Companies before
The Amherst Group
Education
University of RichmondBSBA
University of Texas at AustinMBA
Other boards
none sourced
Known for
Director of Capital MarketsPrivate equityBSBAMBA
Jul 2021 - Present
since https://linkedin.com/in/christopher-white-0565a44

Sources: education

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Holds a BSBA from the University of Richmond and an MBA from the University of Texas at Austin.
value seen: University of Richmond — BSBA; University of Texas at Austin — MBA
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Chris White
value seen: Chris White
https://ldpre.com/

Sources: linkedin page

SOCIALdate not shown in source

Christopher White

LinkedIn · carried by ldpre.com
https://linkedin.com/in/christopher-white-0565a44
value seen: https://linkedin.com/in/christopher-white-0565a44
https://ldpre.com/

Sources: previous companies

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Joined from The Amherst Group
value seen: The Amherst Group
https://ldpre.com/

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Director of Capital Markets
value seen: Director of Capital Markets
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

SOCIALdate not shown in source

Christopher White

LinkedIn
Director of Capital Markets - [Lonestar Development Partners] (Current) Jul 2021 - Present
value seen: Jul 2021 - Present
https://www.linkedin.com/in/christopher-white-0565a44

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Coordinates capital markets activities. Joined from The Amherst Group and has more than 20 years of experience in finance, private equity, and real estate.
value seen: coordinates LDP’s capital-markets activities and joined from The Amherst Group
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Holds a BSBA from the University of Richmond and an MBA from the University of Texas at Austin.
value seen: Director of Capital Markets; 20+ years finance; Private equity; BSBA; MBA
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Chris White Director of Capital Markets
value seen: Director of Capital Markets
https://ldpre.com/
CR
Cindy Rapisand
Cindy Rapisand is LDP’s accounting director and treasurer. The company describes her as a CPA with more than 20 years in real-estate partnerships and reporting; her profile shows a parallel senior accounting role at Bonner Carrington and a regional controller role at Kennedy Wilson.
Current title
Director of Accounting — Treasurer
Experience
20+ years real estate
Companies before
Bonner CarringtonKennedy WilsonBel Mondo Detailed Designs & RemodelsAmerican Federal BankMurray PropertiesErnst & Whinney
Education
Texas A&M UniversityBachelor of Business Administration, Accounting
Other boards
Executive Vice President of Accounting & Finance — Bonner CarringtonRegional Properties Controller — Kennedy Wilson
Known for
CPATreasurerReal-estate reportingBBA Accounting
Nov 2020 - Present
since https://www.linkedin.com/in/cindy-rapisand-0982ab28

Sources: education

SOCIALdate not shown in source

Cindy Rapisand

LinkedIn
### Bachelor of Business Administration (BBA), Accounting at [Texas A&M University]
value seen: Texas A&M University — Bachelor of Business Administration, Accounting
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/cindy-rapisand-0982ab28

Sources: full name

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Cindy Rapisand
value seen: Cindy Rapisand
https://ldpre.com/

Sources: linkedin page

SOCIALdate not shown in source

Cindy Rapisand

LinkedIn · carried by ldpre.com
https://www.linkedin.com/in/cindy-rapisand-0982ab28
value seen: https://www.linkedin.com/in/cindy-rapisand-0982ab28
https://ldpre.com/

Sources: other boards

SOCIALdate not shown in source

Cindy Rapisand

LinkedIn
### Executive Vice President of Accounting & Finance - Bonner Carrington (Current) ... ### Regional Properties Controller - [Kennedy Wilson] (Current)
value seen: Executive Vice President of Accounting & Finance — Bonner Carrington; Regional Properties Controller — Kennedy Wilson
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/cindy-rapisand-0982ab28

Sources: previous companies

SOCIALdate not shown in source

Cindy Rapisand

LinkedIn
### Executive Vice President of Accounting & Finance - Bonner Carrington ... ### Regional Properties Controller - [Kennedy Wilson] ... ### Owner - Bel Mondo Detailed Designs & Remodels ... ### Asset Manager - American Federal Bank ... ### Assistant Controller - [Murray Properties] ... ### Staff Auditor - Ernst & Whinney
value seen: Bonner Carrington; Kennedy Wilson; Bel Mondo Detailed Designs & Remodels; American Federal Bank; Murray Properties; Ernst & Whinney
held out of the figures · the quote does not carry this value
https://www.linkedin.com/in/cindy-rapisand-0982ab28

Sources: role type

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Director of Accounting — Treasurer
value seen: Director of Accounting — Treasurer
no listed category matches this wording, so it is shown as the source wrote it
held out of the figures · no listed category matches this wording
value paraphrased from this source
https://ldpre.com/

Sources: since

SOCIALdate not shown in source

Cindy Rapisand

LinkedIn
Nov 2020 - Present (5 years and 10 months) in Austin TX
value seen: Nov 2020 - Present
https://www.linkedin.com/in/cindy-rapisand-0982ab28

Sources: summary

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Certified Public Accountant and Texas A&M University graduate with over 20 years of experience in real estate partnerships and reporting.
value seen: LDP’s accounting director and treasurer
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: tags

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
Managed accounting for more than $3 billion in real estate assets
value seen: CPA; Treasurer; 20+ years real estate; Real-estate reporting; BBA Accounting
held out of the figures · the quote does not carry this value
https://ldpre.com/

Sources: title

COMPANYdate not shown in source

Lonestar Development Partners — Development Built on Partnership

Lonestar Development Partners · carried by ldpre.com
### Cindy Rapisand Director of Accounting — Treasurer
value seen: Director of Accounting — Treasurer
https://ldpre.com/

Projects

Assessment coverage

Completed projects: 2016-10-16 through 2026-10-16. Initial research is capped at 10 completed projects and a separate delivery-risk search capped at 7 findings. Risk findings are not project assessment counts. Absence is not proof of a complete portfolio or no failures. Month-level dates overlapping a boundary are excluded from figures.

0 undated completions and 0 boundary-uncertain completions are retained but excluded from figures.

Stalled, cancelled & overdue projects

0 evidenced cases
The capped delivery-risk search ran; no project-level exception cases are recorded here. Risk findings are listed under Risks and are separate from assessed projects. This does not establish that the developer has no delivery failures.

Completed projects

5 projects
ProjectLocationTypeUnitsFloorsAreaCostPayment planLaunchedConstruction startOriginal targetHandoverDelayConfidenceStatus
The Landing at LakewayLakeway, United States
residential for sale751two & three-story———20192019Jan 2020Jan 2023 – Dec 2023+41.5 mo
(+36.0 to +47.0)
sourcedcompleted
The Rail at MLKAustin, United States
residential for rent2351five-story117,097 sq ft——2018Dec. 14, 2018Jan 2020 – Dec 2020Feb 2021+7.5 mo
(+2.0 to +13.0)
estimatedcompleted
Trailside OaksLeander, United States
residential for rent1051————20192 April 2019—Jan 2020 – Dec 2020—not scorablecompleted
Bee Caves VistasAustin, United States
Oak Hill
residential for rent891————2016Friday May 6th, 2016Jan 2017 – Mar 2017Jan 2019 – Dec 2019+28.5 mo
(+22.0 to +35.0)
sourcedcompleted
Walden SquarePflugerville, United States
residential for rent8211 & 2——————Jan 2019 – Dec 2019—not scorablecompleted
Click any row for the sources behind it. Cost basis matters: an estimated cost, a construction loan and a sale price are different numbers. Each row states which one it is, so they are never averaged together.

Awards

Awards & recognition

1 found
RANKING Ranked May 12, 2020 (reported by the developer); list published May 8, 2020
Austin-area multifamily real estate development firms — The List
The developer reports that Lonestar Development Partners ranked No. 6 on Austin Business Journal’s list of Austin-area multifamily development firms, based on units under construction; this is a 2020 publication and does not establish a current 2026 ranking.

Risks

Risk flags

3 found
LEGAL Filed April 3, 2026; docket information current through May 18, 2026
A commercial-and-trade contract lawsuit was filed against Lone Star PE, LLC, which is identified in the court docket as doing business as Lonestar Development Partners, and Christopher Kopacek; the defendants filed a general denial, and the case was still open in the retrieved docket information.
DELIVERY DELAY Buyer review dated July 25, 2022; page retrieved September 14, 2026
A buyer review alleged that a townhome at The Landing at Lakeway took years to build and complained of poor craftsmanship, low quality, and that Lonestar Development Partners had not made things right; this is an unverified customer allegation, not a formal finding.
DELIVERY DELAY 2023-12-20 publication; Spring 2026 projected opening; 2026-10-16 research position
Presidio Apartments, a San Antonio project reported as being developed by Lonestar Development Partners, appears overdue: a December 2023 report projected a Spring 2026 opening, while the state project record lists completion for October 1, 2028 and a related commercial building permit remained pending issuance on October 8, 2026; this documents delayed delivery, not abandonment.

Record status

active
Coverageactive
Tracked sinceOctober 10, 2026
Last checkedOctober 16, 2026 this month
Profile last researchedOctober 16, 2026
Claim
Work for this company? Claiming lets you correct the record with sources and get alerts when it changes.
For informational purposes only. This information is not investment, financial or credit advice and should not be relied on for investment, lending or credit decisions. Records may be incomplete or outdated. Verify information independently and seek qualified advice before making a decision.